Ramky Infrastructure Ltd Directors Report.
Your Directors have pleasure in presenting their 25th Annual Report on the business and operations of your company for the financial year ended March 31, 2019. The consolidated performance of the company and its subsidiaries has been referred to wherever required.
The standalone and consolidated financial performance of the Company for the financial year ended March 31, 2019 is summarized below:
(Rs. in Millions)
|Revenue from operations||14,766.52||13,464.37||17,487.63||15,784.97|
|Profit/(Loss) before taxes||469.45||1,029.65||31.13||1,111.14|
|Tax Expense/ (Benefit)||56.90||380.14||31.60||453.17|
|Profit/(Loss) after Tax||412.56||649.51||(0.48)||325.25|
|Earnings per equity shares in INR||7.00||11.03||2.55||4.85|
|Share of loss from associate companies||-||-||-||(332.72)|
Review of Performance and state of the companys affairs Standalone:
During the year under review, members will notice that the standalone revenues from operations have increased to Rs. 14,766.52 Millions from 13,464.37 Millions of the previous year 2017-18. However due to decrease in the other income from Rs. 3,195.36 to Rs. 1,389.45 the profit after tax has decreased to Rs. 412.56 as against profit of Rs. 649.51 Millions in the previous year 2017-18.
During the year under review, members will notice that the consolidated revenues have also increased to Rs. 17,487.63 Millions from Rs. 15,784.97 Millions to the previous year 2017-18.
The consolidated accounts of your Company broadly represents the EPC business plus the investment that have gone into the 13 wholly owned subsidiaries, 7 Subsidiaries, 2 Jointly Controlled entities, 2 Associates & 3 step down subsidiaries of the Company, and the consolidated business represents the consolidation of the EPC business and the integrated infrastructure developer businesses.
In accordance with Regulation 34(2) of the listing agreement and in compliance with the provisions of the Companies Act, 2013 and the Accounting Standards. Your Directors have pleasure in attaching the Consolidated Financial Statements as part of the Annual Report.
A statement containing brief financial details of the subsidiaries for the financial year ended March 31, 2019 is annexed as Annexure - I. The annual accounts of these subsidiaries and the related detailed information will be made available to any member of the Company/its subsidiaries seeking such information at any point of time and are also available for inspection by any member of the Company/its subsidiaries at the registered office of the Company. The annual accounts of the subsidiaries will also be available for inspection, as above, at registered office of the respective subsidiary companies.
In terms of Section 136 of the Companies Act, 2013 the audited financial statements is open for inspection at the Registered Office of the Company. Copies of this statement may be obtained by the members by writing to the Company Secretary at the Registered Office of the Company.
Dividend and Transfer to Reserves
Your Board of Directors has not recommended any dividend for the financial year 2018-19. No amount is transferred to General Reserve during the financial year 2018-19.
During the period under review there is no change in the Authorised share Capital of the Company. The Authorised share capital is Rs. 70,00,00,000 divided into 7,00,00,000 equity shares of Rs. 10/- each and Paid-up Share Capital is Rs. 59,84,77,910 divided into 5,98,47,791 equity shares of Rs. 10/- each.
The Company has not issued any shares with differential rights and hence no information as per provisions of Section 43(a)(ii) of the Act read with Rule 4(4) of the Companies (Share Capital and Debenture) Rules, 2014 is furnished. During the period under review, the Company has allotted 26,50,000 equity shares upon conversion of Compulsorily Convertible warrants issued at face value Rs.10/- each and at premium of Rs. 91.00/-each.
Directors & Key Managerial personnel Composition of Board
The Board of Directors of your company is duly constituted. The Board consists of Eight Directors comprising of Two Executive Directors, One Non-Executive Director, One Nominee Director and four Independent Directors.
Key Managerial Personnel and changes
Following are the Key Managerial Personnel and changes in the Company. Mr. Y.R. Nagaraja Managing Director Mr. I.W. Vijaya Kumar Chief Financial Officer (Resigned w.e.f.31.05.2019) Mr. Sanjay Kumar Sultania Chief Financial Officer (Appointed w.e.f. 31.05.2019) Mr. Akash Bhagadia - Company Secretary The Board of Directors at its meeting held on 13.11.2018, has appointed Mr. Ravikumar Reddy Somavarapu and Dr. Sastry Gangadhara Peddibhotla, as Additional Non-Executive Independent Director on the Board of the Company. The Board of Directors at its meeting held on 13.02.2019 has re-appointed Mr. Murahari Reddy Velpula, as Independent Director of the Company for a further period of 5 years commencing from 31.03.2019, subject to the approval of members in the ensuing General Meeting.
Upon the recommendation of Nomination and Remuneration committee and request of Dr. Anantapurguggilla Ravindranath Reddy, (DIN 01729114), The Board at their meeting held on 13.08.2018 has changed the designation of Dr. Anantapurguggilla Ravindranath Reddy, as Non-Executive Director from Non-Executive Independent Director.
Proposed Appointments / Re-appointments in the 25th Annual General Meeting
(i) Approval of the shareholders is being sought for the appointment of Dr. Anantapurguggilla Ravindranath Reddy, (DIN 01729114) as Director (Non-Executive Non-Independent Director) of the Company, who retire by rotation at the ensuing Annual General Meeting of the Company and being eligible offer himself for re-appointment in accordance with the provisions of the Companies Act and pursuant to Articles of Association of the Company.
(ii) Appr oval of the derssharehol is being sought for the appointing Mr. Ravikumar Reddy Somavarapu as a Non-Executive Independent Director in accordance with the provisions of the Companies Act and pursuant to Articles of Association of the Company.
(iii) Appr oval of the shareholders is being sought for the Dr. Sastry Gangadhara Peddibhotla, as a Non-Executive Independent Director in accordance with the provisions of the Companies Act and pursuant to Articles of Association of the Company.
(iv) Appr oval of the shareholders is being sought for the re-Mr. Murahari Reddy Velpula, as a Non-Executive Independent Director for a further period of 5 years commencing from 31.03.2019 in accordance with the provisions of the Companies Act and pursuant to Articles of Association of the Company.
Board of Directors has proposed for appointment of aforesaid Directors in the ensuing Annual General Meeting of the Company.
Number of meetings of the Board
During the year under review Five Board Meetings were held on 09.04.2018, 30.05.2018, 13.08.2018, 13.11.2018 and 13.02.2019. The intervening gap between any two Board Meetings is within the period prescribed by the Companies Act, 2013 and the Listing Agreement.
Declarations by Independent Directors
The Company has received declarations from the Independent Directors under Section 149(6) of the Companies Act, 2013 and Regulation 25 of SEBI (LODR) Regulations, 2015 confirming their independence vis--vis the Company.
Board evaluation and assessment
The Company believes formal evaluation of the board and of the individual directors, on an annual basis, is a potentially effective way to respond to the demand for greater board accountability and effectiveness. For the company, evaluation provides an ongoing means for directors to assess their individual and collective performance and effectiveness. In addition to greater board accountability, evaluation of board members helps in-a) More effective board process b) Better collaboration and communication c) Greater clarity with regard to members roles and responsibilities d) Improved chairman managing directors and board relations The evaluation process covers the following aspects
- Self-evaluation of directors
- Evaluation of the performance and effectiveness of the board
- Evaluation of the performance and effectiveness of the committees
- Feedback from the non-executive directors to the chairman
- Feedback on management support to the board.
Familiarization Programme for Independent Directors
The Company shall through its Senior Managerial Personnel familiarize the Independent Directors with the strategy, operations and functions of the Company. The Independent Directors will also be familiarized with their roles, rights and responsibilities and orientation on Statutory Compliances as a Board Member.
On appointment of the Independent Directors, they will be asked to get familiarized about the Companys operations and businesses. An Interaction with the key executives of the Company is also facilitated to make them more familiar with the operations carried by the company. Detailed presentations on the business of the company are also made to the Directors. Direct meetings with the Chairman and the Managing Director are further facilitated for the new appointee to familiarize him/her about the Company/its businesses and the group practices as the case may be and link is available at the website www.ramkyinfrastructure.com
Directors Responsibility Statement
Pursuant to the requirement under section 134 (3) and (5) of the Companies Act 2013, with respect to Directors Responsibility Statement, your board of directors to the best of their knowledge and ability confirm that: appointinga. in the preparation of the annual accounts, the applicable accounting standards had been followed along with proper explanation relating to material departures; b. such accounting policies have been selected and applied consistently appointing and the Directors made judgments and estimates that are reasonable and prudent so as to give a true and fair view of the state of affairs of the Company as at 31st March, 2019 and of the profit of the Company for that year; c. proper and sufficient care was taken for the maintenance of adequate accounting records in accordance with the provisions of this Act for safeguarding the assets of the Company and for preventing and detecting fraud and other irregularities; d. the annual accounts of the Company have been prepared on a going concern basis; e. internal financial controls have been laid down to be followed by the Company and that such internal financial controls are adequate and were operating effectively; f. proper systems have been devised to ensure compliance with the provisions of all applicable laws and that such systems were adequate and operating effectively;
Constitution and Composition of Audit Committee
The Audit Committee of the company is duly constituted as per Section 177 of the Companies Act, 2013. Composition and Scope of Audit Committee is provided under the Corporate Governance report annexed herewith.
In pursuance of Regulation 17 to 27 read with Schedule V of SEBI (Listing Obligations & Disclosure Requirements) Regulations, 2015, entered into with the Stock Exchanges, a separate Report on Corporate Governance along with a certificate from Mr. N.V.S.S. Suryanarayana Rao, Practicing Company Secretary, regarding its compliance is annexed and forms part of this Report. Your Company will continue to adhere in letter and spirit to good corporate governance policies.
Management Discussion & Analysis
In terms of the provisions of Regulation 34 of the SEBI (Listing Obligation and Disclosure Requirements) Regulations, 2015, The Management Discussion and Analysis Report highlighting the industry structure and developments, opportunities and threats, future outlook, risks and concerns etc. is furnished separately and is set out in this report.
Members of the Company in the 24th Annual General Meeting held on 25.09.2018 has appointed M/s. M.V. Narayana Reddy & Co., (FRN.No: 002370S), Chartered Accountants as Statutory Auditors of the Company for a period of 5 years to carry out audit for financial year 2018-19 to 2022-23.
The Ministry of Corporate Affairs vide its notification dated 7th May, 2018, has dispensed with the requirement of ratification of Auditors appointment by the shareholders, every year. Hence, the resolution relating to ratification of Auditors appointment is not included in the notice of the ensuing Annual General Meeting.
Reporting of Fraud
The Auditors of the Company have not reported any frauds specified under Section 143(12) of the Companies Act, 2013.
Cost Audit Report
Pursuant to the provisions of Section 148 of the Companies Act, 2013 and as per the Companies (Cost Records and Audit) Rules, 2014 and amendments thereof, read with Notifications/Circulars issued by the Ministry of Corporate Affairs from time to time, the Board of Directors at their meeting dated 13.08.2018, appointed M/s. S R and Associates, Cost Accountants as the Cost Auditors of the Company for the financial year 2018 19. The Board approved their appointment for the FY 2018-19. The Cost Audit Report will be filed within the stipulated period of 180 days from the closure of the financial year.
A proposal for approval of remuneration of the Cost Auditor for financial year 2018-19 is placed before the shareholders.
Business Responsibility Report (BRR)
Securities Exchange Board of India (SEBI) vide circular CIR/CFD/DIL/8/2012 dated August 13, 2012 has mandated the inclusion of BRR as part of the Annual Report for the top 100 listed entities based on their market capitalization on Bombay Stock Exchange Ltd and National Stock Exchange of India Ltd as at 31 March 2012. In view of the requirements specified, the Company is not mandated for the providing the BRR and hence do not form part of this Report.
Corporate Social Responsibility
Ramky Infra has been pursuing CSR activities long before they were made mandatory under the Companies Act, 2013. You are aware that the CSR activities are being carried under Ramky Foundation, a charitable trust which looks after CSR activities. It focuses on 4 thrust areas viz, natural resource management, education, health and women empowerment. It seeks to bring corporate sector with an overall aim to create equitable, sustainable, and accessible developmental opportunities for the communities we serve.
A Report on Corporate Social Responsibility (CSR) Policy and Activities as per Rule 8 of Companies (Corporate Social Responsibility Policy) Rules, 2014 is appended to this annual report as Annexure II and link to the CSR policy is available at the website www.ramkyinfrastructure.com.
The Company complies with all applicable secretarial standards.
Particulars of Loans, Guarantees and Investments
Details of loans and guarantees given and investments made under Section 186 of the Act are provided in the Notes to the Financial Statements provided in this Annual Report.
Secretarial Audit Report
Pursuant to the provisions of Section 204 read with Section 134(3) of the Companies Act, 2013, the company is required to obtain Secretarial Audit Report from Practicing Company Secretary. Mr. N.V.S.S. Suryanarayana Rao, Practicing Company Secretary was appointed to issue Secretarial Audit Report for the financial year 2018-19.
Secretarial Audit Report issued by Mr. N.V.S.S. Suryanarayana Rao, Practicing Company Secretary in Form MR-3 for the financial year 2018-19 forms part to this report as Annexure III.
Management responses to observations in Secretarial Audit Report:
The following are the responses of the management against the observations made by the Secretarial Auditor:
|Sl. No||Observations||Management replies/ response|
|1.||Company is yet to submit the Annual Performance Report of Ramky Engineering and Consulting Services (FZC), wholly owned foreign Subsidiary with RBI.||Management to ensure the timely compliance and to submit the Annual Performance report to RBI without further delay.|
|2.||As on March 31, 2019, undisputed dues in respect Provident Fund, Employees State Insurance and Gratuity, have not been regularly deposited with the appropriate authorities and there have been delays in number of cases;||Management to ensure that existing systems are more tightened and that the compliances are being carried out without any delay|
|3.||There was delay in filing of prescribed forms with MCA beyond time limit of 30 days, but within 300 days and in respect of which Company has paid additional fee.||Company will ensure timely compliances.|
|4.||Mr. Y R Nagaraja, Managing director and Mr. A Ayodhya Rami Reddy, Wholetime Director of the company has created a pledge on the shares of the company during the closure of trading window from 24th May, 2018 to 02nd June, 2018.||Documents with respect to pledge of shares were executed prior to closure of trading window. However, because of procedural delay the pledge on shares were executed on 25th May, 2018 i.e., during the closure of trading window.|
|5.||In pursuance of Section 124(6) of the Companies Act, 2013, Company has not transferred the shares in respect of which dividend has not been paid or claimed for seven consecutive years or more in the name of Investor Education and Protection Fund.||All the compliance with respect to transfer of unclaimed and un paid dividend is completed. However, because of conversion of physical shares into demat, there was a delay in transfer of shares in respect of which dividend has not been paid or claimed for seven consecutive years or more in the name of Investor Education and Protection Fund.|
As required under the provisions of SEBI LODR Regulations, a certificate confirming that none of the Directors on the Board have been debarred or disqualified by the Board/Ministry of Corporate Affairs or any such statutory authority obtained from Mr. N.V.S.S. Suryanarayana Rao, Practicing Company Secretaries is a part of the Corporate Governance report.
Management responses to observations in Auditors Report
With reference to observations made in Auditors Report, the notes of account is self-explanatory and therefore do not call for any further comments. The results for the year ended March 31, 2019 have been subjected to an audit by the Statutory Auditors of the Company without qualification.
|S. No.||Emphasis of Matters in Standalone Financials||Companys comments/remarks|
|1||Ramky Infrastructure Limited : Material uncertainties exist over the realisability of certain construction work-in-progress aggregating to Rs. 996.12 million which are subject matter of arbitration proceedings/negotiations with customers and contractors due to foreclosure of contracts and other disputes.||The Management of the Company, keeping in view the long term nature of contracts, terms and conditions implicit in these contracts and the ongoing discussions, based on which, steps to recover are currently in process and is confident of recovering the amount as they are contractually tenable.|
|2||Srinagar Banihal Expressway Limited / Ramky Infrastructure Limited: Cost overrun of the project to the extent of Rs 3,679.03 million including taxes accounted during the year.||Srinagar Banihal Expressway Limited had subcontracted the turnkey EPC contract of the four laning of the section on the Srinagar Banihal National Highway 1A in the state of J&K to Ramky Infrastructure Limited at a lumpsum consideration of Rs 11,750 million in the year 2011. The construction period for the project was for a period of three years. Due to delays beyond the control and scope of the Contractor, the Contractor had to incur additional cost in terms of price and quantity variations. Hence there is a cost over run cost of Rs.3,679.03 million (inclusive tax)|
|1||Ramky Infrastructure Limited : Material uncertainties exist over the realisability of certain construction work-in-progress aggregating to Rs 996.12 million which are subject matter of arbitration proceedings/negotiations with customers and contractors due to foreclosure of contracts and other disputes.||The Management of the Company, keeping in view the long term nature of contracts, terms and conditions implicit in these contracts and the ongoing discussions, based on which, steps to recover are currently in process and is confident of recovering the amount as they are contractually tenable.|
|2||Srinagar Banihal Expressway Limited / Ramky Infrastructure Limited: Cost overrun of the project to the extent of Rs 3679.03 million including taxes accounted during the year.||Srinagar Banihal Expressway Limited had subcontracted the turnkey EPC contract of the four laning of the section on the Srinagar Banihal National Highway 1A in the state of J&K to Ramky Infrastructure Limited at a lumpsum consideration of Rs 11,750 million in the year 2011. The construction period for the project was for a period of three years. Due to delays beyond the control and scope of the Contractor, the Contractor had to incur additional cost in terms of price and quantity variations. Hence there is a cost over run cost of Rs.3,679.03 million (inclusive tax)|
|3||Srinagar Banihal Expressway Limited:|
|The Company could not meet its borrowing obligations with the lenders during the year, as a result of which loan accounts with various banks had become NPA.||Srinagar Banihal Expressway Limited has been sanctioned term loan of Rs.14,400 Million to construct the Highway i.e., four laning of section on the Srinagar Banihal National Highway 1A.|
|However due to delays beyond the control of the Company, the project had both time over run and cost over run cost. Since the project has achieved the PCOD, it has been decided that in the absence of being funded by the Lenders and Promoters, to use the annuity proceeds on completing the project instead of incurring the interest and principal obligation. Hence it has become an NPA Account.|
|4||Hospet Chitradurga Tollways Limited :|
|Termination of the project by the Company & NHAI. Since the Company is a project specific Company, termination of the project affects the Going Concern nature of the Company.||The Company has been incorporated to undertake Road project under PPP Mode. However, the project could not materialise.|
|The investments made in this project having been impaired in the Accounts, the Company is in the process of approaching ROC / MCA for strike off the name from the Register.|
|5||Ramky Pharma City (India) Limited :|
|Uncertainty in connection with the Charge sheet filed by CBI and attachment order of the ED in respect of certain assets of the Company.||On an appeal preferred by the Company before the Appellate Tribunal against the attachment order of ED, the Tribunal partly allowed the appeal by modifying both impugned orders until the final decision is given by the Special Court on Merit.|
|Accordingly the Appellate Tribunal directed the ED to restore the possession of 60 unsold plots valued INR.224.50 Millions. However, the attachment shall continue in respect of 50 mtrs inward as buffer zone inside the Pharma City till the dispute is finally decided / vacated by the Special Court. The remaining all attached properties are released forthwith.|
Whistle Blower Policy/Vigil Mechanism
Pursuant to the provisions of Section 177 of the Companies Act, 2013 and the rules framed there under and pursuant to the applicable provision of SEBI (LODR) Regulations, 2015, the company has established a mechanism through which all stake holders can report the suspected frauds and genuine grievances to the appropriate authority. The Whistle blower policy which has been approved by the board of directors of the company has been hosted on the website of the company www.ramkyinfrastructure.com Risk Management Framework
Pursuant to SEBI (LODR) Regulations, 2015, the Board of Directors of the top 100 Listed entities are mandated to constitute a Risk Management Committee. Since the Company is not falling under the above criteria, there is no requirement to constitute such a committee.
However, periodic assessments to identify the risk areas are carried out and management is briefed on the risks in advance to enable the Company to control risk through a properly defined plan. The risks are taken into ac- count while preparing the annual business plan for the year.
Policy on Sexual Harassment
The Company has adopted policy on Prevention of Sexual Harassment of Women at Workplace in accordance with The Sexual Harassment of Women at Workplace (Prevention, Prohibition and Redressal) Act, 2013. During the financial year ended 31st March, 2019, the Company has not received any complaints pertaining to Sexual Harassment.
Particulars of Contracts or arrangements with related parties
All the related party transactions that were entered during the financial year were in the ordinary course of business of the company and were on an arms length basis. There were no materially significant related party transactions entered by the company during the year with the promoters, directors, key managerial personnel or other persons which may have a potential conflict with the interest of the company.
The policy on related party transactions as approved by the board of directors is hosted on the website of the company www.ramkyinfrastructure.com Particulars of every contract or arrangements entered into by the Company with related parties referred to in sub-section (1) of section 188 of the Companies Act, 2013 including certain arms length transactions under third proviso thereto shall be disclosed in Form No. AOC-2 is appended as Annexure-IV to the Boards report.
Material changes and commitments, if any, affecting the financial position of the company
There are no material changes and commitments affecting the financial position of the company which occurred between the end of the financial year to which the financial statements relate and the date of the report.
Details of significant and material orders passed by the regulators or courts or tribunals impacting the going concern status and companys operations in future
No significant and material order has been passed by the regulators, courts, tribunals impacting the going concern status and Companys operations in future.
Your Company has not accepted any fixed deposits, including deposits from the public. As such, there was no principal or interest outstanding on the date of the Balance Sheet.
Material Subsidiary Policy
The Company has adopted a policy for determining material subsidiary, in line with the requirements of the Listing Agreement. The Policy on Material Subsidiary is available on the website of the Company at www.ramkyinfrastructure.com Remuneration Policy
The Board has on the recommendation of Nomination and remuneration Committee approved a policy for selection and appointment of Directors, Key Managerial Personnel, Senior Management and their remuneration. The policy of the Company on Directors appointment and remuneration, including the criteria for determining the qualifications, positive attributes, independence of a director and other matter as required under sub section (3) of Section 178 of the Companies Act, 2013 is available on the website of our Company at www.ramkyinfrastructure.com Particulars of Employees
A table containing the particulars in accordance with the provisions of Section 197(12) of the Act, read with Rule 5(1) of the Companies (Appointment and Remuneration of Managerial Personnel) Rules, 2014, is NIL
The ratio of the remuneration of each Director to the median employees remuneration and other details in terms of Section 197(12) of the Companies Act, 2013 read with Rule 5 of the Companies (Appointment and Remuneration of Managerial Personnel) Rules, 2014, are enclosed in Annexure V and forms part of this Report.
Extract of the Annual Return
In accordance with Section 134 (3) (a) of the Act, an extract of the Annual Return in the prescribed format is placed on the website of the company www.ramkyinfrastructure.com.
Particulars of Conservation of Energy, Technology Absorption and Foreign Exchange Earnings and Outgo
Conservation of Energy which is an ongoing process in the Companys construction activities and the same is not furnished as the relevant rule is not applicable to your company.
There is no information to be furnished regarding Technology Absorption as your company has not undertaken any research and development activity in any manufacturing activity nor any specific technology is obtained from any external sources which needs to be absorbed or adapted.
Innovation is a culture in the Company to achieve cost efficiency in the construction activity so as to be more competitive in the prevailing environment.
Foreign Exchange Earnings and Outgo
In accordance with the provisions of Section 134 of the Companies Act, 2013, read with the Companies (Disclosure of Particulars in the Report of Board of Directors) Rules, 1988, the information relating to foreign exchange earnings and outgo is provided under Notes to the Balance Sheet and Profit and Loss Account.
Internal Audit & Controls
The Company has appointed M/s. JKMR & Co, as its Internal Auditors for the financial year 2018-19 Their scope of work includes review of processes for safeguarding the assets of the Company, review of operational efficiency, effectiveness of systems and processes, and assessing the internal control strengths in all areas. Internal Auditors findings are discussed with the process owners and suitable corrective actions taken as per the directions of Audit Committee on an ongoing basis to improve efficiency in operations.
Internal Financial Control Systems
The Company has adequate Internal Financial Controls consistent with the nature of business and size of the operations, to effectively provide for safety of its assets, reliability of financial transactions with adequate checks and balances, adherence to applicable statues, accounting policies, approval procedures and to ensure optimum use of available resources. These systems are reviewed and improved on a regular basis. It has a comprehensive budgetary control system to monitor revenue and expenditure against approved budget on an ongoing basis.
The company enjoyed cordial relations with its employees during the year under review and the Board appreciates the employees across the cadres for their dedicated service to the Company, and looks forward to their continued support and higher level of productivity for achieving the targets set for the future.
Listing with Stock Exchanges
The equity shares of your Company are listed on the National Stock Exchange and the Bombay Stock Exchange, Mumbai. The Company has been complying with the regulations as prescribed under SEBI (LODR) Regulations, 2015. The Company confirms that it has paid the Annual Listing Fees for the year 2018-19 to NSE and BSE where the Companys Shares are listed.
Your Company treats its "human resources" as one of its most important assets.
Your Company continuously invests in attraction, retention and development of talent on an ongoing basis. A number of programs that provide focused people attention are currently underway. Your Company thrust is on the promotion of talent internally through job rotation and job enlargement
Your Directors wish to express their appreciation of the support and cooperation of the Central and the State Government, bankers, financial institutions, suppliers, associates and subcontractors and seeks their continued patronage in future as well.
|For and on behalf of the Board of|
|RAMKY INFRASTRUCTURE LIMITED|
|A. AYODHYA RAMI REDDY||Y.R. NAGARAJA|
|Whole-time Director||Managing Director|
|DIN: 00251430||DIN: 00009810|